MahaRERA भी Builder को ही Favour करता है ? Buyer लड़ेगा तो ही जीतेगा!
Вставка
- Опубліковано 23 сер 2024
- 𝐅𝐢𝐥𝐥 𝐲𝐨𝐮𝐫 𝐑𝐞𝐚𝐥 𝐄𝐬𝐭𝐚𝐭𝐞 𝐐𝐮𝐞𝐫𝐢𝐞𝐬 𝐟𝐨𝐫 𝐪𝐮𝐢𝐜𝐤 𝐚𝐬𝐬𝐢𝐬𝐭𝐚𝐧𝐜𝐞👉🏻 www.saudaghar....
SaudaGhar Presents-
Key Takeaways from MahaRERA Appellate Tribunal's Landmark Judgment
Impugned Order Summary:
In May 2021, MahaRERA passed orders concerning complaints filed by flat purchasers against the promoter of the "F-Residences" project in Pune. The initial complaints were about the delay in possession and non-payment of pre-EMI by the promoter. MahaRERA's orders allowed flat purchasers to either continue in the project under the original terms or withdraw as per the agreement conditions, not accounting for the provisions of Section 18 of the Act.
1. Appellate Tribunal's Landmark Judgment- The MahaRERA Appellate Tribunal, in a significant judgment, set aside the previous orders of MahaRERA, bringing forth several crucial points:
2. Absolute Possession Date- The Tribunal emphasised that the possession date mentioned in the sale agreement is absolute and sacrosanct, rejecting any extensions even if grace periods are mentioned.
3. Unconditional Rights of Allottees- It affirmed the unconditional rights of allottees to seek a refund under Section 18 of the Act, irrespective of unforeseen events or regulatory delays not attributable to the allottee.
4. Right to Amend Complaints- The Tribunal acknowledged the right of complainants to alter their relief claims during the litigation process, such as switching from seeking possession to demanding a refund.
5. Promoter's Accountability- It was held that the promoter's failure to deliver possession on the agreed date constitutes solid grounds for the refund of the paid amount to the flat purchasers.
6. Final Order- The Tribunal directed the promoter to refund the paid amounts, including taxes, with interest, within a specified time frame, marking a significant victory for the complainants.
Important: SaudaGhar’s Insight for Home Buyers-
This judgment serves as a powerful precedent, reinforcing the rights of home buyers against unfair practices and delays by developers. It highlights the importance of the registered agreement’s terms and safeguards the interests of buyers in real estate transactions. As part of SaudaGhar's commitment to empowering buyers, we emphasize the significance of this ruling in upholding buyers' rights and the accountability of developers.
Stay informed and empowered with SaudaGhar, your partner in making informed real estate decisions.
𝐖𝐡𝐚𝐭𝐬𝐀𝐩𝐩 𝐮𝐬 𝗬𝗼𝘂𝗿 𝗥𝗲𝗮𝗹 𝗘𝘀𝘁𝗮𝘁𝗲 𝗤𝘂𝗲𝗿𝗶𝗲𝘀👉 wa.me/message/...
***** 𝐄𝐱𝐭𝐞𝐫𝐧𝐚𝐥 𝐋𝐢𝐧𝐤𝐬 *****
Impugned MahaRERA Order👉🏼 www.saudaghar....
Appellate Tribunal Order👉🏼www.saudaghar....
***** 𝐑𝐞𝐥𝐚𝐭𝐞𝐝 𝐕𝐢𝐝𝐞𝐨 𝐋𝐢𝐧𝐤𝐬 *****
Landmark Order by High Court 👉🏻 • MahaRERA से त्रस्त Buy...
-------------------------------------------------------------------------------------------------------------------
𝗦𝗮𝘂𝗱𝗮𝗚𝗵𝗮𝗿 𝗪𝗵𝗮𝘁𝘀𝗔𝗽𝗽 𝗖𝗵𝗮𝗻𝗻𝗲𝗹 𝗟𝗶𝗻𝗸👉🏼 whatsapp.com/c...
𝐒𝐚𝐮𝐝𝐚𝐆𝐡𝐚𝐫 𝐔𝐩𝐝𝐚𝐭𝐞𝐬👉🏼 ig.me/j/Aba5WG...
𝐕𝐢𝐝𝐞𝐨 𝐂𝐡𝐚𝐩𝐭𝐞𝐫𝐬;
00:00 Intro
Think Real Estate, Think SaudaGhar!
𝐅𝐨𝐫 𝐟𝐮𝐫𝐭𝐡𝐞𝐫 𝐚𝐬𝐬𝐢𝐬𝐭𝐚𝐧𝐜𝐞 𝐲𝐨𝐮 𝐦𝐚𝐲 𝐜𝐚𝐥𝐥 𝐮𝐬 𝐚𝐬 𝐰𝐞𝐥𝐥: +𝟗𝟏- 𝟕𝟎𝟑𝟎𝟕𝟕𝟏𝟐𝟑𝟒
--------------------------------------------------------------------------------------------------------
𝐘𝐨𝐮 𝐌𝐚𝐲 𝐜𝐡𝐞𝐜𝐤 𝐒𝐚𝐮𝐝𝐚𝐆𝐡𝐚𝐫 𝐖𝐞𝐛𝐬𝐢𝐭𝐞 & 𝐎𝐭𝐡𝐞𝐫 𝐒𝐨𝐜𝐢𝐚𝐥 𝐌𝐞𝐝𝐢𝐚 𝐏𝐥𝐚𝐭𝐟𝐨𝐫𝐦𝐬:
𝗪𝗲𝗯𝘀𝗶𝘁𝗲👉 www.saudaghar....
𝗜𝗻𝘀𝘁𝗮𝗴𝗿𝗮𝗺👉 / saudaghar
𝗧𝘄𝗶𝘁𝘁𝗲𝗿👉 / saudaghar
𝗟𝗶𝗻𝗸𝗲𝗱𝗜𝗻👉 / 35500454
𝗙𝗮𝗰𝗲𝗯𝗼𝗼𝗸👉 / saudagharproperties
𝗢𝗻𝗲 𝗟𝗶𝗻𝗸 𝗳𝗼𝗿 𝗮𝗹𝗹👉 linktr.ee/saud...
------------------------------------------------------------------------------------------------------------------------------------
𝗗𝗶𝘀𝗰𝗹𝗮𝗶𝗺𝗲𝗿: The information presented in this video is solely intended for informational purposes, with the primary objective of conveying information to the audience. SaudaGhar does not assert the absolute accuracy of all facts disclosed herein. It is acknowledged that human error is inherent. Users are advised to exercise their discretion while making decisions. The utilization of this video for purposes other than informational is expressly disclaimed.
This video will definitely help buyers to fight against builder. Thank you
Obviously, Builders, RERA or politics are just different faces of the same coin
Eye opener video for buyers who are in trouble
Buyer pe ye responsibility hi kyu aati hai?.....agar possession nahi milta hai to rera complaint raise karte hi builder k sare account and new project approvals freeze ho jane chahiye. builder ko jab tension milega tabhi kuch hoga....buyer kyu ghumega court to court.
Hara vahi jo ladha nahi,
This is very common actually people when they make mistakes or getting cheated they don't want to come forward and take some action, instead they just keep quiet and live with that burden for the rest of their life.
Very Useful Information... Everywhere Builders are looting innocent buyers.
Right
These buildes are chor and looters all builders must go to jail
This is because of we PPL r innocent, let's all be no more innocent, stop building flats and we come to cities like Noida Pune etc to make builder rich not to do job because most part of our job we give to them
Great efforts in deep diving in technicalities.. much needed. Keep up the good work
Sir pune west mei WTC pe video banaaiye, its has been stuck post excavation for quite sometime now.
🙏👌
As a common investor who can buy 1 or 2 small flats it makes zero sense to fight with a builder. Nyay shaayad milega but after lakhs or rupees and years of fighting. Buy only OC ready place. Leave UC projects to HNIs.
I buyed flat 1 BHK from dagade Patil constructions project white prestige bavdhan builder is saying give money than take possession all other have gone there by paying money cheque taking possession without taking documents like OC , possession letter the date was on agreement was JUN 23 now there is Feb I am daily calling builder he saying same give money take possession and builder will not give any documents and saying give remaining balance amount and then He will give keys of flat there have been 7 month passed and on rera website completion date is DECEMBER 23 But on agreement date is June 23 sir can now I file campliant on rera website sir please reply I have paid him till date more than 80% amount of total consideration
Sir please make video on bavdhan location
We are going to create a video on the same topic today. It will clear all your doubts.
Or builder can only sell flats post oc received... No one allowed to sell project at beginning. Only such practice must exist.
Simple project not completed on time disbursement from escrow account. No new approval for project....
Sir can we get details of the lawyer
Sir one question- if we went to appellate court in this process, do we have to take the possession or not?
No, you cannot take possession. If you wish to take possession, you can request the Appellate Tribunal during the hearing.
@@SaudaGhar thank you sir.
With all your videos and knowledge . Me and few more buyers filed RERA complaint against rama builder. Hope we get justice
Please name the builder too
You may check it from the order copy, link below in the description.